Permitting Report via DeepResearch
Report: “Global Permitting Processes: A Comparative Analysis and Policy Innovations”
Executive Summary
Infrastructure and energy projects often face protracted permitting processes that can significantly delay construction and increase costs. This report provides a comprehensive, data-driven analysis of permitting systems in the United States, key EU nations (Germany, France, UK), China, and Japan over the past 25 years. We compare the frameworks, timelines, and challenges across these jurisdictions and identify best practices and policy innovations that could inform U.S. reforms. Major findings include: (1) U.S. environmental review under the National Environmental Policy Act (NEPA) averages multiple years to complete, with extensive multi-agency involvement and litigation risk contributing to delays. (2) European Union countries operate under the EU Environmental Impact Assessment (EIA) Directive, but national approaches vary – Germany and France have introduced measures to streamline reviews and limit legal appeals in recent years, while the UK’s 2008 planning reforms set statutory timelines for major projects. (3) China’s centralized, top-down permitting system enables faster approvals – often within months – by concentrating authority and limiting public contestation, though sometimes at the expense of rigorous environmental and social oversight (GAO-24-106866, International Infrastructure Projects: China’s Investments Significantly Outpace the U.S. and Experts Suggest Potential Improvements to the U.S. Approach). (4) Japan’s process, modeled after NEPA, remains lengthy and complex, particularly hindering new clean energy developments.
Despite differences, common themes emerge. Permitting delays are a critical bottleneck for infrastructure delivery and climate goals in many countries. For example, achieving net-zero emissions by 2050 is deemed “procedurally impossible” under current U.S. permitting timelines (Is Fast-41 Permitting All That Fast? Why Congress Must Take a More Serious Approach to Streamlining Federal Permitting). However, several jurisdictions have pioneered solutions: one-stop-shop permitting agencies, streamlined environmental reviews, digital permit platforms, and fast-track legal procedures, all of which maintain environmental standards while expediting decisions. Notable cases – such as Denmark’s accelerated wind project approvals and the U.S. Bureau of Land Management’s programmatic solar reviews – demonstrate that smart reforms can cut years off project timelines.
Methodology: This report draws on a range of sources, including government data (e.g., U.S. Council on Environmental Quality reports, Congressional Research Service analyses), international regulatory databases (OECD, World Bank), and academic and think-tank studies. We reviewed official documents like the U.S. Permitting Dashboard, EU Commission reports, China’s National Development and Reform Commission (NDRC) guidelines, and Japan’s Ministry of Economy, Trade and Industry (METI) publications. Quantitative data on permitting durations, approval rates, and legal challenges were gathered where available to support the comparative analysis. All information is cited from credible sources to ensure accuracy and depth.
1. Permitting Process Overview
This section describes the permitting frameworks in each region – the United States, European Union (with focus on Germany, France, and the UK), China, and Japan – highlighting key laws, responsible agencies, environmental review requirements, and typical timelines for major infrastructure projects. A comparative summary of timelines and approval rates follows to contextualize differences.
United States
The U.S. permitting process for large infrastructure is governed by a complex framework of federal, state, and local laws. NEPA (National Environmental Policy Act of 1969) is the cornerstone federal law requiring environmental review of major projects. Under NEPA, federal agencies must assess the environmental impacts of “major federal actions” by preparing documents such as Environmental Assessments (EAs) or more rigorous Environmental Impact Statements (EISs). The Council on Environmental Quality (CEQ) oversees NEPA implementation and issues regulations that agencies follow in preparing these reviews. Multiple other federal statutes often intersect with NEPA reviews – for example, the Clean Water Act, Clean Air Act, Endangered Species Act, National Historic Preservation Act, and others impose additional permit requirements, each administered by different agencies. A single infrastructure project in the U.S. may require dozens of permits from federal and state agencies, leading to a fragmented process.
Governing Bodies: There is no single “permitting agency” at the federal level; instead, authority is dispersed. For transportation projects, the U.S. Department of Transportation (and state DOTs) take the lead; for energy projects, agencies like the Federal Energy Regulatory Commission (FERC) or Department of Energy may be involved; for projects on federal land, the Bureau of Land Management (BLM) or U.S. Army Corps of Engineers (USACE) issue key permits. The result is often concurrent jurisdiction, with one agency serving as NEPA lead and others as cooperating agencies, but each still rendering separate permit decisions. In recent years, efforts have been made to improve interagency coordination – e.g. the establishment of the Federal Permitting Improvement Steering Council under the FAST-41 Act (2015) aims to coordinate complex project reviews.
Environmental Review Requirements: NEPA requires agencies to consider alternatives, consult with the public and expert agencies, and document potential impacts. An EIS typically involves scoping, a draft EIS with public comment, and a final EIS, culminating in a Record of Decision. This process is thorough but time-consuming. According to CEQ data, a typical EIS took an average of ~4.5 years to complete (median 3.5 years) in the 2010s, and often ran hundreds of pages. Federally funded highway projects have been especially slow, averaging nearly 7 years for NEPA review. These timelines often exceed the time required for actual construction. On the other hand, less intensive Environmental Assessments (EAs) are usually completed in under a year (e.g. ~9.6 months on average for recent Department of Transportation EAs), and many smaller projects qualify for Categorical Exclusions with minimal review.
Timelines and Approval Rates: While most projects that enter NEPA review eventually obtain approval, the lengthy timelines are a defining feature. In 2020, the CEQ reported a median EIS completion time of 3.5 years, but recent reforms have begun to shorten this: by 2024 the median was down to 2.2 years from Notice of Intent to final EIS, reflecting a ~28% reduction in timeline due to streamlining efforts. Even so, large projects frequently face delays beyond the NEPA process due to subsequent permitting steps and litigation (discussed in Section 2). The approval rate for permit applications is not formally tracked in aggregate; agencies do not often “deny” projects outright in the EIS stage – instead, projects may be withdrawn or stalled. Overall, the U.S. system is characterized by thorough analysis and multiple veto points, with slower approvals compared to many other countries.
European Union (Germany, France, UK)
Permitting in EU countries occurs within the framework of EU environmental law as well as national laws. The EU EIA Directive (Directive 2011/92/EU, as amended) requires member states to conduct an environmental impact assessment for certain categories of projects. This directive, originally adopted in 1985 and updated multiple times (most recently in 2014), sets minimum standards for transparency, public participation, and consideration of impacts for projects like highways, power plants, large industrial facilities, etc. Each member state has transposed these requirements into its domestic legislation and designated authorities to oversee the process. In addition, the EU’s Habitat and Birds Directives can require Appropriate Assessments for impacts on protected nature sites (Natura 2000 areas), adding another layer of review.
Despite the common EU framework, permitting processes vary by country: some have centralized models, others delegate heavily to regional or local authorities. Generally, EU nations aim for shorter review timelines than the U.S. – consultant studies for EIA reports may take only a few months – but administrative procedures and appeals can introduce delays. We examine Germany, France, and the UK as three distinct examples:
Germany
Germany’s permitting system is rooted in federal laws that incorporate EU directives. The principal environmental law is the Federal Immission Control Act (Bundes-Immissionsschutzgesetz, BImSchG), which establishes an integrated permit requirement for facilities that may cause harmful environmental effects. Projects such as industrial plants, large infrastructure, and energy facilities generally need a license under BImSchG, which in turn triggers an EIA for projects likely to have significant impacts. Germany’s Environmental Impact Assessment Act (Umweltverträglichkeitsprüfungsgesetz) spells out EIA procedures, aligning with the EU EIA Directive’s requirements on screening, scoping, and public participation. Key federal agencies include the Federal Ministry for the Environment (BMUV) and the Federal Environment Agency (UBA), but much of the permitting work is carried out by state (Länder) authorities since Germany is a federal system.
Notably, German law emphasizes mitigation and offsetting of environmental impacts. The Federal Nature Conservation Act requires that unavoidable impacts on nature be compensated (the “encroachment regulation”), making mitigation a formal part of permit approval. This can add complexity but also clarity in requirements for project developers.
Timelines: Germany has struggled with permitting delays in certain sectors. Onshore wind energy projects, for instance, slowed in recent years due to planning and permitting bottlenecks – projects have faced lengthy zoning battles and lawsuits (e.g., over impacts to wildlife or landscape aesthetics). In contrast, offshore wind has benefited from recent reforms: Germany passed laws to accelerate offshore wind permitting, including a 2022 amendment that created a one-stop federal authority (the BSH – Federal Maritime and Hydrographic Agency) to handle all approvals for offshore wind farms. This consolidated process has significantly cut down approval times for offshore projects. Another example of acceleration is Germany’s response to the 2022 energy crisis – it enacted an LNG Acceleration Act to fast-track liquefied natural gas import terminals, resulting in projects being approved and built in months rather than years.
Approval rates and oversight: German authorities tend to approve most projects that meet regulatory standards, but the process of getting to approval can be onerous. Public participation is robust – public hearings and objection periods are required. Legal challenges have historically been a major cause of delay; recognizing this, in March 2023 Germany enacted sweeping litigation reforms to expedite permit-related lawsuits for key infrastructure. These reforms limit the suspensive effect of lawsuits and aim to resolve cases faster, indicating the urgency Germany attaches to streamlining without gutting environmental protections.
France
France’s permitting process for infrastructure is centralized to a greater degree than Germany’s. An array of permits (environmental, construction, land use) historically applied, but France has moved toward unification of permits. In 2017, it introduced a single “environmental authorization” that consolidates various approvals (except building permits) for projects, simplifying the application process (). The French Code de l’environnement implements the EU EIA Directive, requiring études d’impact (impact studies) and public inquiries for many projects. The Ministry for Ecological Transition and its regional offices (DREALs) oversee environmental assessments, while other ministries (e.g., Industry, Energy) and local prefects have decision-making roles depending on project type.
Timelines: In practice, getting a full permit in France can take a couple of years, but the major challenge has been legal appeals. France had a notorious issue with renewable energy projects, especially onshore wind, being tied up in court. Nearly 70% of wind farm authorizations in France have been appealed by opponents, creating protracted uncertainty (). These judicial reviews add “several years” on average to project timelines (). Recognizing this problem, France reformed its litigation process for wind projects – since 2018, appeals on wind permits go directly to the Administrative Courts of Appeal as a court of first and last instance, bypassing intermediate courts (). This was intended to cut down the legal battle duration. Moreover, France in 2023 passed a law to accelerate renewable energy deployment, including measures like identifying priority zones for renewables and limiting the time for authorities to respond to applications (Government seeks to speed up activists' appeals of wind farms) (halving the time to realize wind projects was a stated goal). These steps are relatively recent, so their full effect on timelines is still being observed.
Approval rates: French regulators do sometimes reject projects on environmental grounds (for instance, if a proposed wind farm would violate protected species rules or heritage site protections, it might be denied or downsized). However, more commonly, projects are approved with conditions, and then the courts become the forum where projects are delayed or stopped. A high-profile example is the Nant offshore wind farm, which endured nearly a decade of legal challenges before proceeding. The government’s reforms signal an effort to maintain environmental scrutiny while curbing “abusive” appeals. As a result, while France’s permitting process is formally streamlined and similar in length to other EU countries, the de facto timeline to a fully unchallenged approval had been among the longest in Europe – something now improving with the legal changes.
United Kingdom
The United Kingdom overhauled its infrastructure permitting system with the Planning Act 2008, which created a distinct process for Nationally Significant Infrastructure Projects (NSIPs). This covers large energy generation facilities, major transportation links, etc. Under the NSIP regime, developers apply to the Planning Inspectorate (a national body) for a Development Consent Order (DCO), which serves as a unified consent replacing various separate permits. The process includes a pre-application consultation (where developers must engage local communities and prepare an environmental statement akin to an EIA), followed by an examination by an Inspectorate panel, and a final decision by the relevant Secretary of State (minister). Importantly, the timeline is largely codified: once an application is accepted for examination, the examination stage is capped at 6 months (with recent provisions for a fast-track 4-month examination for some cases) (Planning for nationally significant infrastructure projects), and thereafter the Secretary of State has a further 3 months to issue a decision. This statutory timeline (approximately one year from acceptance to decision) lends greater predictability.
Governing bodies: The Planning Inspectorate manages the hearings and examination. Environmental regulation in the UK (until 2020, following EU rules) ensures projects go through EIA and Habitats assessments during this process. Local authorities are involved mainly at the pre-application stage and as participants in the hearings, but they no longer have veto power over NSIPs – this national consent supersedes local planning permission.
Timelines and outcomes: In practice, UK NSIP projects often take about 2–4 years from initiation to final consent, including the pre-application phase (which can be lengthy as developers do surveys and consultations). However, once in the formal process, the timeline is efficient relative to many countries. For example, the examination of a recent highway improvement or offshore wind farm DCO typically runs on schedule (6 months), and decisions are usually made within the 3-month target. Judicial challenges in the UK must be filed quickly (within 6 weeks of the decision) and are handled by the High Court on limited grounds (usually procedural legality). While some projects have been quashed in court (e.g., a roads plan halted over climate impact considerations), this is the exception. Most NSIPs are approved and proceed to construction; the approval rate is high, as the system is designed to integrate policy considerations upfront (if a project aligns with national policy statements, it’s likely to be permitted). Overall, the UK model emphasizes predictability and centralized decision-making, balancing local input with national needs.
China
China’s infrastructure permitting is characterized by strong central control, rapid decision-making, and a focus on economic development goals. The primary environmental review law is the Environmental Impact Assessment Law (enacted 2002), which requires that all large construction projects undergo an EIA approval before construction. The Ministry of Ecology and Environment (formerly the State Environmental Protection Administration, SEPA) oversees EIA enforcement, but much authority is delegated to provincial and local Environmental Protection Bureaus. Unlike the U.S. and EU systems where EIA is a process to inform a separate permit decision, in China the EIA approval is itself a clearance that a project must obtain (projects also need other permits like land use approvals, but those are generally obtained through government plan inclusion). Notably, China’s EIA Law mandates public participation for projects with significant environmental impacts – a provision added in 2003 and strengthened after some high-profile incidents where projects began without proper EIA clearance. Public meetings and comment periods are required, and project documents should be disclosed.
However, the Chinese system remains fundamentally top-down. Large projects, especially those in strategic sectors (energy, transport, water infrastructure), often follow national plans (e.g., Five-Year Plans, sector masterplans). If a project is in line with these plans, the political will to execute it is strong. China also uses strategic environmental assessments and spatial planning tools to guide development. For instance, the “Three Lines, One Permit” (TLOP) policy introduced around 2017 divides regions into zones with ecological red lines, environmental quality bottom lines, resource utilization ceilings, and a permit system to enforce these limits. Within this framework, individual projects that meet criteria can be expedited.
Permitting Efficiency: China is known for extremely fast permitting timelines on marquee projects. It is not uncommon for a major railway or power plant to get its EIA and other necessary approvals in a matter of months. For example, the Beijing–Shanghai high-speed railway (1,318 km) was reportedly completed in about 4 years from start to finish, including obtaining all approvals and construction – a pace made possible by streamlined approvals and political prioritization. Local governments host “one-stop” service centers to help investors navigate permit requirements, and there is often a single “window” for project approval at the local Development and Reform Commission (DRC) office, especially for foreign-invested or large domestic projects. In essence, when a project has political backing, the coordination between agencies is handled internally by the government, not left to the developer. Environmental review is done quickly by approved consulting firms and reviewed by expert panels.
Environmental and Social Trade-offs: The speed of China’s process can come at a cost. While laws exist on paper for thorough EIA and public oversight, enforcement has been inconsistent. In the mid-2000s, SEPA launched an “environmental storm” clampdown – halting dozens of projects that had begun construction without EIA approval. This indicates that local officials sometimes proceeded with development before environmental clearance. Weaknesses in environmental governance have been noted: some projects under the Belt and Road Initiative (BRI) had “weak environmental, social, or governance standards,” according to reports (GAO-24-106866, International Infrastructure Projects: China’s Investments Significantly Outpace the U.S. and Experts Suggest Potential Improvements to the U.S. Approach). Public opposition in China typically has limited formal avenues (no equivalent of broad standing for NGOs to sue), though there have been environmental protests that led authorities to cancel or relocate projects (e.g., chemical plants). Overall, approval rates are very high – if a project is proposed by a state entity and fits the plan, it is almost always approved. The emphasis is on mitigating impacts rather than potentially rejecting projects for environmental reasons. China’s system thus achieves rapid approvals and construction (a competitive advantage in infrastructure deployment), but relies on top-down enforcement to ensure environmental standards are met, with varying success.
Japan
Japan’s permitting framework blends stringent environmental requirements with a historically fragmented bureaucracy. Japan’s modern environmental policy began with the Basic Environment Law of 1993, which laid the foundation for comprehensive environmental governance. Pursuant to that law, Japan enacted the Environmental Impact Assessment Act of 1997 (often just called the EIA Act). This law requires project proponents to conduct an EIA for designated project types, which include roads, railways, dams, airports, power plants, and other large developments. Projects are categorized: Class-1 (large projects always requiring EIA) and Class-2 (mid-sized projects that undergo a screening to determine if an EIA is needed). Uniquely, the Japanese EIA Act places the onus on project proponents to prepare the environmental assessment and consider its findings in their project design. In other words, the developer (which could be a private company or a government agency building infrastructure) must evaluate its own project’s impacts and propose mitigation. This is done through a defined process of scoping, draft EIS, public comments, and final EIS, broadly similar to NEPA.
Governing structure: The process is overseen by the Ministry of the Environment (MoE), which reviews EIA reports and provides opinions, but actual project approval decisions are often made by other ministries. For example, a new power plant might be ultimately authorized by the Ministry of Economy, Trade and Industry (METI) or a new highway by the Ministry of Land, Infrastructure, Transport and Tourism (MLIT). This “multi-agency” situation resembles the U.S. in that sector-specific authorities make the final call, with the environmental agency in an advisory role. Local governments in Japan also have a say – they can impose additional environmental conditions and they manage permits related to local pollution control and land use.
Clean energy and recent changes: Japan has been trying to expedite renewable energy projects as part of its climate commitments, but with mixed results. In 2019, the International Energy Agency noted that lengthy EIA procedures are a key challenge for Japan’s onshore and offshore wind deployment. Indeed, an offshore wind project in Japan can take 4-5 years to move through planning and EIA phases before construction, which is slower than in many European countries. To address this, Japan introduced a law in 2018 to identify promotion zones for offshore wind (under the Act on Promotion of Use of Territorial Waters for Renewable Energy), which pre-coordinates some environmental and use-conflict issues to facilitate projects. Additionally, Japan’s EIA Act was amended in 2011 to strengthen follow-up (monitoring after project approval) and enhance transparency, but these did not dramatically shorten the front-end timeline. There is discussion in Japan about further reform, learning from European models to create clearer time limits and central coordination, but changes have been incremental.
Timelines and approvals: Gaining all necessary approvals in Japan for a large infrastructure project typically takes several years. For example, a major highway might require ~3-5 years from proposal through EIA to final go-ahead. A hallmark of the Japanese system is thorough consultation and consensus-building – agencies often seek agreement among stakeholders (including local communities) through dialogue, which can prolong the pre-approval phase but arguably reduces conflict later. Japan generally avoids outright rejection of projects; instead, projects are modified to address concerns. The approval rate for those that complete the EIA process is high. However, there have been instances of projects being effectively canceled due to local opposition or political decision (not so much due to the permitting agencies denying them, but because sponsors pulled out under pressure). In summary, Japan’s process ensures environmental considerations are woven into project design (developers must “bake in” mitigation from the start), but the decentralized, consensus-driven approach leads to slow decisions, akin to the U.S. experience. Efforts to speed up, especially for clean energy, continue as a policy focus.
Comparison of Permitting Timelines and Approval Rates: The table below summarizes typical permitting durations and outcomes in each region for major projects:
Region | Typical Timeline for Major Projects | Approval Tendencies & Notes |
---|---|---|
United States | Multiple years for full environmental review. EIS processes average ~4.5 years (median 3.5), with recent reforms bringing median down to ~2.2 years. Total permitting (including post-EIS permits) often 5–10 years for complex projects. | High scrutiny but few formal denials. Most projects eventually get approved, though many are delayed or modified. Litigation is common, affecting timelines rather than approval outcomes. |
Germany | 1–3 years typical for planning approval of large projects under BImSchG/EIA, though onshore wind projects have faced longer delays (several years) due to court challenges and planning disputes. Recent laws target <2-year approvals for renewables and LNG. | Strong environmental standards; approvals granted with mitigation requirements. High rate of legal challenges in some sectors (e.g., ~600+ court cases on wind in 2010s), prompting 2023 reforms to accelerate court decisions. |
France | 1–2 years for instruction of permit applications under the unified environmental authorization. However, appeals can add 2–7 years extra (). Government aims to halve wind project timelines with new reforms (Government seeks to speed up activists' appeals of wind farms). | Administrative approval rate is high (most projects meeting criteria are approved). But ~70% of wind farm permits were appealed by opponents (), causing extended uncertainty. Reforms in 2018–2023 seek to streamline dispute resolution. |
United Kingdom | 1.5–3 years from application to consent for NSIPs (including pre-app). Once accepted, examination ≤6 months (4 months fast-track) and decision in 3 months (Planning for nationally significant infrastructure projects). Overall, large projects often ~2–4 years including early stages. | Centralized “DCO” consents have a high approval rate – most projects aligned with policy get approved. Rigorous examination, but political rejection is rare. Limited window for judicial review (6 weeks) keeps legal delays short. |
China | Months to 1 year for approvals of large state-priority projects. Environmental permit and other clearances are often concurrent. Some projects start within <6 months of proposal. E.g., major high-speed rail completed in ~4 years including all permits and construction. | Very high approval likelihood if project is in government plan. Environmental and social concerns are addressed via conditions or compensation rather than project denial. Public opposition seldom halts projects (few legal avenues for challenges (GAO-24-106866, International Infrastructure Projects: China’s Investments Significantly Outpace the U.S. and Experts Suggest Potential Improvements to the U.S. Approach)). |
Japan | Several years (3–5 years common) for major projects to clear EIA and obtain all consents. Offshore wind farms, for example, have ~4+ year lead times for permitting. Incremental improvements are ongoing to reduce this. | Tends toward consensus: approvals usually granted after lengthy consultation and often with project modifications. Rare for a project to be outright refused by regulators; more often, delays or local political pressure can derail projects before completion of permitting. |
Table: Indicative permitting timelines and outcomes for major infrastructure projects by region (data compiled from sources and case studies in text).
Note: The above timelines are generalizations – individual project timelines can vary widely depending on project complexity, public controversy, and specific streamlining measures in place. Approval tendencies assume projects that formally enter the permitting process; some proposals never advance due to feasibility or community resistance.
2. Challenges in the U.S. Permitting System
The United States faces a number of challenges in its permitting system that contribute to the extended timelines and uncertainty highlighted above. Key issues include the broad scope and stringency of NEPA reviews, conflicts between overlapping federal and state authorities, the prevalence of litigation and local opposition, and sector-specific impediments (notably in renewable energy, transportation, and industrial projects). This section analyzes these challenges:
NEPA and Environmental Review Timelines
NEPA’s thorough process often lengthens project development schedules. By design, NEPA requires a detailed examination of environmental impacts and alternatives, which improves decision quality but also means years of study. Many agencies, fearing legal vulnerability, prepare exceedingly lengthy EIS documents to defend against any possible challenge. The average final EIS runs over 600 pages and consumes tens of thousands of staff hours. Until recently, there were no statutory limits on how long an EIS could take. Agencies might spend years in internal analysis before even releasing a draft. For example, a “typical EIS takes on average 4.5 years to prepare” under NEPA, a timeline that has become a benchmark in policy discussions. This has real impacts: project construction cannot begin until reviews are complete, so these years represent delayed investment and benefits.
The impact of NEPA is perhaps most evident in sectors like transportation. A Government Accountability Office study found major highway projects could spend 6–8 years in planning and NEPA studies. One illustrative comparison: a complex highway-and-rail project in the U.S. spent about seven years in permitting before construction could start, whereas a similar project (Sydney Gateway motorway) in Australia completed its environmental planning in just two years. Such contrasts put a spotlight on U.S. process inefficiencies. Part of the delay under NEPA comes from its sequential nature – multiple agencies might do separate analyses on the same project. Although NEPA regulations allow “joint” documents and a lead agency concept, in practice coordination can be slow. Each agency has its own mandates and often conducts separate consultations (for instance, the U.S. Fish and Wildlife Service must do an Endangered Species Act consultation, the Army Corps handles wetlands under the Clean Water Act, etc.). Synchronizing all these reviews is challenging.
Moreover, NEPA has what some call a “first-mover disadvantage”: being the oldest EIA law (effective 1970), it has accumulated decades of case law and procedural requirements. Other countries that adopted EIA laws later often learned to achieve similar environmental protection with more efficiency. In the U.S., attempts to update NEPA procedures have been cautious. There have been some improvements – e.g., One Federal Decision, an executive initiative in 2017, aimed to cap EIS timelines at 2 years and consolidate documents, and the recent Fiscal Responsibility Act of 2023 codified presumptive time limits (2 years for EIS, 1 year for EA) and page limits (150 pages generally) for NEPA reviews. Early data suggest progress: the median EIS time dropped to 2.2 years in 2024. Still, implementing these changes across all agencies is ongoing, and there is often resistance to rushing analyses given the legal stakes.
In sum, NEPA’s expansive analytical scope and the lack of binding deadlines historically have been a core challenge. Project sponsors must navigate a lengthy process with uncertain end dates, which can deter investment. Balancing thorough environmental stewardship with timeliness remains an unresolved tension in the U.S. system.
Federal vs. State and Local Regulatory Conflicts
Another layer of complexity arises from the U.S.’s federalist system – projects frequently need both federal permits and state/local permits, which can conflict or cause duplication. For instance, a new energy pipeline might require a federal certificate from FERC and various state permits (state water quality certification, air permits, local zoning approvals, etc.). States have significant authority under laws like the Clean Water Act’s Section 401, which gives states (and tribes) the power to veto or condition federal permits if a project could harm state water quality. In recent years, some states have exercised this power to block projects: New York used Section 401 to deny a water quality certification for a natural gas pipeline, effectively stopping the project, and Washington State similarly denied certification for a coal export terminal. These actions reflect legitimate state environmental concerns, but they also highlight a tension – even if a project passes federal review, state-level disapproval can halt it. The result is a patchwork where infrastructure that crosses multiple jurisdictions (pipelines, interstate transmission lines) can be particularly hard to build. Proponents have to satisfy the most stringent regulator at each level, and one authority’s denial can override others.
Local regulations and politics further complicate matters. Even when federal law aims to preempt local authority (for example, FERC’s permit might override local objections for interstate gas pipelines), in practice local permits (building permits, road access permits) and public opinion play a role. Projects can be delayed by local zoning hearings or even denied building permits at the county level, forcing developers to litigate or seek state intervention. A notable scenario is renewable energy siting: wind and solar farms may have federal environmental reviews (especially if on federal land or involving federal funds), but they also must comply with county ordinances and state siting laws. Local opposition has led some counties to enact moratoria or strict ordinances effectively blocking wind projects, even if they meet federal criteria.
There are also cases of regulatory overlap that cause inefficiency. For instance, an offshore wind project in federal waters needs federal approval (from the Bureau of Ocean Energy Management), but also may trigger state Coastal Zone Management Act reviews and local port permits. Without a unified process, projects end up going through sequential approvals that can stretch timelines. In recognition of this, some states and the federal government have tried cooperative agreements – e.g., California has an agreement to essentially perform NEPA on behalf of the federal government for highway projects (NEPA assignment), which has moderately sped up delivery by removing one layer of duplication.
Federal-state conflicts sometimes also play out in court: states or NGOs may sue federal agencies for issuing permits (arguing they failed to consider something), or conversely project proponents might sue states for unreasonable permit denials. This legal tug-of-war contributes to delays and uncertainty. A prominent debate is whether to limit state veto powers for interstate projects; proposals to reform Section 401 of the Clean Water Act have been floated, aiming to prevent states from using it in ways seen as unrelated to water quality. The previous federal administration (2017–2020) attempted to curb state 401 powers, while the current one has restored them, reflecting differing philosophies on federalism and environmental control.
In summary, misaligned authority and inconsistent standards across federal, state, and local levels create a challenging maze for project developers. A project can clear one hurdle only to be stopped by another, leading to protracted negotiation and sometimes project cancellation. Aligning these levels (through better coordination or legislative clarification of roles) is a key challenge to streamlining permitting.
Litigation and Public Opposition
Litigation is perhaps the most cited cause of delay in U.S. infrastructure permitting. After a permit is granted or an EIS is finalized, opponents can sue on various grounds – alleging violations of NEPA (inadequate review), the Endangered Species Act, Clean Water Act, etc. Such lawsuits can result in projects being remanded for further study or even vacated. The risk of litigation is “the main source of cost, delay, and uncertainty” in NEPA, as one analysis noted. Agencies, anticipating lawsuits, often over-document their EIS to create a defensible record (leading to the aforementioned voluminous studies). Despite best efforts, almost any large EIS has some vulnerability. Federal courts hold agencies to a high standard of reasoned decision-making – a single oversight (sometimes as small as a missing discussion of a minor issue) can lead to a NEPA violation finding. This potential outcome incentivizes a very cautious approach by agencies, slowing the process (“paralysis by analysis”).
Who litigates? Often, local community groups or national environmental NGOs file suit, but increasingly even project competitors or ideological opponents use litigation as a tool. For example, in energy projects, it’s not uncommon for environmental groups to sue over inadequate climate analysis, while landowner groups might sue over eminent domain issues, and sometimes rival companies encourage or support lawsuits to stall competition. The mere possibility of court action means a project isn’t truly “shovel ready” even after permits – it may spend additional years in court. Data from the Department of Justice indicated that only a small percentage of EISs are litigated (on the order of <5%), but those tend to be the largest, most impactful projects, and for those, litigation is almost guaranteed.
Public opposition doesn’t only manifest in court. During the NEPA process itself, public comments can slow things down. Agencies must respond to substantive comments in the final EIS. Highly controversial projects can generate tens of thousands of comments (sometimes form-letter campaigns, sometimes very detailed technical critiques). Agencies then spend time addressing these, which can expand the scope of analysis. For instance, a community might demand the agency analyze an alternative route for a transmission line; the agency, to be thorough, might then include that in a supplemental analysis, adding months to the timeline. NEPA’s public participation is vital for democracy and often improves projects, but it also provides a platform for opponents to create delay as a strategy. This is especially true for “linear projects” (like pipelines, transmission lines) that traverse long distances: every locality along the route might raise unique objections, compounding the complexity.
Once permits are issued, even if litigation is not pursued, opponents can use other means to delay: protests and direct action (e.g., the Dakota Access Pipeline saw prolonged protests that, while outside the permitting process, influenced political decisions to revisit permits), or lobbying for additional reviews (requesting a supplemental EIS on new information). The U.S. system, valuing due process, often entertains these challenges, which is good for accountability but bad for speed. As one study observed, local opposition can subordinate national priorities, meaning even if a project is nationally important (a transmission line for grid reliability), it can be stalled by a relatively small group of local objectors through the available legal mechanisms.
Impacts of litigation: Beyond time, the threat of litigation shapes agency behavior – leading to very conservative, paperwork-heavy approaches. It can also deter investors from pursuing projects at all, known as the “chilling effect.” For example, developers of interstate power lines have cited the uncertain permitting and litigation landscape as a reason for slow build-out of grid infrastructure in the U.S. compared to Europe.
In response, some reforms aim to reduce litigation delays: FAST-41 (discussed later) imposes a 2-year statute of limitations for lawsuits on covered projects, compared to the default 6 years under the Administrative Procedure Act ([PDF] Federal Infrastructure Permitting FAST-41 Reforms and What's Next ...). Some have proposed specialized courts for infrastructure or limiting injunctions for projects of national significance. And as noted, countries like Germany have implemented measures like concentrating legal jurisdiction in higher courts to speed decisions () – ideas that U.S. policymakers are examining. Nonetheless, any such changes face controversy because they potentially restrict communities’ ability to challenge government decisions.
Sector-Specific Delays
Certain sectors face unique permitting hurdles:
-
Renewable Energy and Transmission: Ironically, the projects needed for clean energy transition – wind farms, solar arrays, high-voltage transmission lines – often encounter significant delays under the current system. For renewables on federal land, NEPA reviews can be drawn-out (though BLM has tried programmatic approaches to streamline, like pre-designating “solar energy zones”). Offshore wind, which involves federal waters, must navigate lengthy environmental assessments (including novel issues like impacts on fisheries and marine life). Furthermore, the “Not In My Backyard” (NIMBY) syndrome is prevalent for wind projects; local opposition over aesthetics or wildlife has halted or delayed numerous onshore wind farms, even after federal review. As a result, to meet climate goals, experts note that permitting reform is essential – without it, adding the required renewable capacity in time is “procedurally impossible” (Is Fast-41 Permitting All That Fast? Why Congress Must Take a More Serious Approach to Streamlining Federal Permitting). Another piece is transmission lines: they often cross multiple states and counties, each with veto power, and there is no single federal permit for interstate electricity lines (unlike pipelines). This has led to notoriously slow development of transmission – a critical issue since wind/solar need new lines to connect to cities. Efforts are underway (e.g., DOE’s designation of National Interest Electric Transmission Corridors and funding incentives), but permitting remains the top barrier.
-
Transportation (Highways, Transit, Rail): Large transportation projects frequently use federal funds, thus triggering NEPA. These also involve extensive community consultation and right-of-way acquisition. A highlight challenge is High-Speed Rail (HSR) in the U.S. – projects like California’s HSR have spent over a decade in environmental review and approvals, segment by segment. The California HSR’s first tier EIS was done in 2005, but final route segments are still getting cleared in the 2020s. By contrast, countries like China built entire HSR systems in that period. Urban transit projects also face multi-year reviews and sometimes get reevaluated mid-course, causing resets. The multitude of funding sources (federal, state, local) can introduce overlapping reviews (each with its own requirements).
-
Industrial and Energy Facilities: This includes pipelines, mines, refineries, chemical plants, LNG export terminals, etc. These projects not only require NEPA (if federal permits or funding apply) but also a suite of direct permits: Clean Air Act New Source Review permits, Clean Water Act discharge permits, etc., often requiring Best Available Control Technology analyses and public hearings at the state level. For example, opening a new mine on federal land can require an EIS by the Bureau of Land Management, plus state mining permits, which combined can take 7-10 years – one reason cited for why the U.S. has difficulty expanding domestic mining for critical minerals (Congressional action on energy permitting remains stuck, but states ...). Oil and gas pipelines have had high-profile delays (Keystone XL, for instance, underwent a decade of NEPA reviews and court fights before being canceled). Nuclear energy deserves special mention: The U.S. Nuclear Regulatory Commission (NRC) licensing process for new reactors is extremely intensive, involving safety design certification and environmental review. The only new nuclear plant built in recent decades, Plant Vogtle units 3 and 4 in Georgia, started the federal permitting process in 2006 and is expected to enter operation in 2024, highlighting an ~18-year journey. NRC’s licensing is partly to blame, but so are legal challenges and the sheer complexity of nuclear regulations. This timeline effectively dissuades proposals for new nuclear plants – a point often raised in debates about achieving energy goals.
-
Infrastructure Maintenance and Upgrades: Even projects to rebuild or upgrade existing infrastructure (like raising a dam or widening an existing highway) can face lengthy reviews. Though categorical exclusions exist for some maintenance, anything involving expansion triggers full reviews. This slows down improvements and climate adaptation projects (e.g., strengthening levees or relocating roads from flood zones).
In each sector, the consequence of delay is different: for renewables, it hampers emissions reduction; for transport, it perpetuates congestion and limits economic growth; for industrial projects, it can push development overseas or mean continued reliance on older facilities. The common denominator is that the current U.S. permitting system is not consistently delivering decisions in a timeframe commensurate with investment and policy needs. It’s important to note that delay does not always equal denial – many projects eventually get built, but the slow pace can inflate costs and deter some projects entirely.
The following sections (3 and 4) will compare how other jurisdictions manage similar challenges and highlight reforms and best practices that might alleviate these issues while still upholding environmental protections.
3. International Comparison
How does the United States’ permitting system stack up against those of the EU, China, and Japan? This section provides a comparative analysis, focusing on key differences in regulatory frameworks, average timelines, approval rates, and the role of legal challenges. By examining international approaches – from the EU’s rule-bound but increasingly streamlined processes, to China’s rapid but centrally-managed system, to Japan’s NEPA-inspired framework – we can identify patterns and lessons. The comparison is structured around two themes: (a) Permitting timelines and approval rates, and (b) Environmental review rigor and legal challenges.
Permitting Timelines and Approval Rates
One of the starkest contrasts is in the speed of approvals. Broadly, the U.S. has the longest permitting timelines for major projects among the regions considered. European countries tend to have faster processes on paper, though certain projects (especially in Western Europe) still encounter multi-year delays. China is the fastest, often by an order of magnitude, and Japan falls in between Europe and the U.S. in terms of speed.
-
United States: As detailed, an EIS can take 3-5 years or more, and full project permitting often exceeds 5 years. It’s not unusual for big projects to spend a decade from proposal to construction start due to reviews and litigation. The approval rate (projects that eventually get the green light) is relatively high for those that persevere, but many proposals are abandoned along the way. For instance, of major energy projects proposed in the past decade, numerous pipeline and mining projects were shelved after permitting delays made them uneconomical or after adverse court rulings. Thus, the U.S. system can act as a filter that stops some controversial projects entirely (which supporters see as communities defending themselves, and critics see as stifling investment).
-
European Union (Germany, France, UK): The EU’s EIA Directive imposes assessments but does not dictate how long they should take – that is left to each country’s procedures. Germany traditionally had thorough processes somewhat akin to the U.S., but in recent years it has focused on expediting renewable energy permits. Germany introduced legal deadlines for certain processes and reporting requirements to monitor permitting progress. For example, Germany’s Renewable Energy Sources Act now presses authorities to speed up grid expansion and renewables siting. On average, a German planning approval (Planfeststellungsverfahren) for infrastructure might take around 1-2 years, if uncontested. However, as noted, many are contested, adding years in court. Still, Germany’s timeline for uncontested cases is better than the U.S., partially because many reviews run in parallel under a single proceeding (the Planfeststellung can incorporate all necessary assessments and stakeholder inputs at once). France has made a push to reduce what was an average of about 4-5 years for onshore wind projects (from conception to operation) down to 2-3 years. The half-dozen offshore wind farms tendered in 2012 in France illustrate the old timeline: they received initial permits by 2016 but were stalled by litigation until 2019 in some cases (A new horizon for offshore wind energy in France | White & Case LLP). The government’s recent streamlining aims to ensure that once a permit is granted, the final court ruling happens within ~18 months, providing more certainty. The UK, with its statutory one-year examination/decision period for NSIPs, stands out as having one of the most predictable systems. Many NSIP projects do stick close to the envisioned timeline, meaning the UK can sometimes go from application to approval in 1.5 years, plus however long the developer spent preparing the application. This is considerably faster than U.S. federal projects. For instance, the Hinkley Point C nuclear plant in the UK navigated the NSIP process and got its Development Consent in about 18 months (granted in 2013), which is impressively swift for a nuclear project (the remaining years until construction were mainly for financing and design finalization). In terms of approval rates, Europe seldom outright rejects projects for which an EIA has been done – instead, they impose conditions or require modifications. Most cancellations occur if the proponent withdraws or if political winds shift funding priorities. One interesting metric: In France, from 2008-2018, only a handful of EIAs resulted in a project being stopped by the authorities; the majority were approved, many with conditions (aside from those caught in legal appeals). In Germany, local resistance has blocked some projects (like Stuttgart 21 rail project faced huge protests but ultimately moved forward). The UK’s approval rate for NSIPs is above 90%, as the regime is meant to implement national policy – only a few applications have been refused (some nuclear projects were withdrawn before decision due to economics; a few highway projects have been refused due to environmental concerns).
-
China: Chinese timelines are often astonishingly short by Western standards. Many infrastructure projects get their necessary approvals in under a year. Part of this is due to parallel processing – Chinese officials convene all relevant departments to review a project concurrently. The concept of a “single-window” approval is often applied in special economic zones or pilot cities, where a lead agency handles the inter-agency coordination. Moreover, the timeline is a mandate: officials are tasked by superiors to deliver projects quickly (in line with Five-Year Plans or specific targets), so there is strong political pressure to avoid delay. As a result, China was able to build ~20,000 km of high-speed rail in a decade, deliver huge solar and wind installations, and construct mega-projects (dams, bridges) in timeframes unimaginable in the U.S. The approval phase is rarely the rate-limiting step in China – financing or construction practicalities are. Approval rates are effectively 100% for projects endorsed by the government. If a project is in the national plan, the question is not if it will be approved, but how quickly and under what conditions. That said, China has occasionally pulled the plug on projects after approval if problems arise (often due to environmental accidents or public outcry, e.g. chemical factory explosions leading to cancellations of similar planned facilities). But those are exceptions to an overall high execution rate. It’s worth noting that international indices reflect China’s efficiency: the Global Infrastructure Hub reports strong improvement in China’s permit processes since 2017, and the World Bank’s former “Doing Business” survey consistently showed China cutting red tape in obtaining construction permits (in 2019-2020 Beijing and Shanghai were reported to take just 90-130 days to issue all construction permits for a model commercial warehouse, whereas many U.S. cities took longer).
-
Japan: Japan’s timelines are moderately long. A review of cases suggests that obtaining an environmental approval under the EIA Act often takes 1.5 to 3 years from the time the developer submits the first scoping document to the final environmental document approval. Then other permits (for example, a development permit under city planning law, various construction and operational permits) add more time. Overall, large projects can spend ~3-7 years in the planning/permitting stage in Japan, which, while shorter than worst-case U.S. scenarios, is slower than the EU average. Japan’s approval rate is high for projects that reach conclusion – the bureaucracy works with the proponent to resolve issues and rarely says “no” outright. However, Japan’s public acceptance can be a hurdle – community agreement is often sought, and if local opposition is fierce (for example against a new airport runway or a controversial dam), the project can be postponed indefinitely by political decision even if permits were in process.
In terms of numbers, it is difficult to give precise averages (because of varying methodologies of measurement), but a pattern emerges: China (months) < UK (~1-2 years) < Germany/France/Japan (~2-5 years, depending on project and appeals) < USA (5-10+ years for major projects). These differences in timeline significantly affect how quickly countries can build new infrastructure or respond to crises (as seen when Germany fast-tracked LNG terminals in under a year in 2022, something the U.S. would struggle to do under normal procedures).
Environmental Review Rigor and Legal Challenges
All regions require environmental reviews, but the breadth and depth of analysis, and the avenues for legal challenge, differ greatly.
The United States arguably has the most rigorous and adversarial review system. NEPA demands analysis of direct, indirect, and cumulative impacts, consideration of alternatives (including the “no action” alternative), and responses to public commentary. The resulting documents (EIS) can be encyclopedic. Moreover, because NEPA is procedural (agencies must take a “hard look” but can still choose an environmentally damaging option), stakeholders use the process to push agencies to adopt less harmful alternatives or more mitigation. Coupled with parallel laws like the Clean Water Act Section 404 (which has a substantive requirement to avoid wetlands if possible) and the Endangered Species Act (which can outright forbid actions that would jeopardize a species), the U.S. ensures a high level of environmental scrutiny. On the downside, this complexity provides multiple legal hooks for opponents. NEPA itself allows lawsuits on whether the process was followed correctly. Other statutes like ESA allow lawsuits on the substantive outcome (e.g., if an agency permits something that might harm a listed species, they can be sued for violating the ESA’s provisions). The availability of injunctive relief – courts can halt a project while a lawsuit is pending – means agencies tend to be extremely cautious. As mentioned, litigation is common enough that it’s a defining feature of the U.S. system. Importantly, U.S. courts are relatively accessible: public interest groups have standing to sue if they can show environmental harm to their members, and the courts have independent power to review agency decisions. This judicial oversight, while ensuring accountability, introduces uncertainty (a project isn’t safe even after getting permits).
In the European Union, environmental review is also taken seriously, but the approach differs. The EIA Directive and Habitat Directive impose thorough assessments, but many EU countries integrate these into the broader permitting decision rather than treating them as separate hurdles. For example, in Germany or France, the outcome of an EIA is directly used by the permitting authority to impose conditions or require project changes. The process is somewhat less adversarial – public consultations happen, but once a permit is granted, the expectation is that environmental issues have been addressed to an acceptable degree. Legal challenges in Europe are possible (and common in some countries), but they typically focus on whether proper procedure was followed and whether the final decision appropriately balanced considerations. Europe also has something the U.S. lacks: binding planning regimes. Many decisions are guided by spatial plans or policy plans (e.g., zoning that already earmarks locations for certain infrastructure). If a project fits the plan, the environmental review might be more straightforward (impacts are known/expected from that zone). Europe’s substantive environmental requirements, like air quality standards or water framework directive, are enforced, but often outside the project permitting context (i.e., they might force overall improvements, but not necessarily stop one project).
When it comes to litigation, Europe has a mixed picture. Germany: individuals and environmental NGOs have the right to challenge permits, and they have done so frequently (especially for wind farms, grid lines, and large industrial projects). Recognizing the delays, Germany’s 2023 law now channels all big infrastructure cases directly to the higher administrative courts to get faster rulings. Germany also set stricter criteria for who has standing in some cases and tried to limit injunctive relief for projects of overriding public interest (so that, for instance, a highway might be allowed to proceed with construction on non-disputed segments even if another segment is held up in court). France: historically, even a single resident could file an appeal (requête) against a permit, and cases crawled through the courts. The reforms giving exclusive competence to appellate courts for wind projects were meant to both elevate and speed the process (). France also moved to a “full merits” review for environmental cases, meaning the court can modify a permit rather than just annul it – this is important because it can avoid the all-or-nothing outcomes and instead fix issues without restarting the whole process (). UK: In the UK, there is no broad EIA lawsuit per se; one can challenge a DCO on judicial review principles (was the law followed, was the decision rational). Only parties with a direct stake can challenge easily (usually local authorities or NGOs with a longstanding interest). Challenges must be filed quickly, and courts there have tended to be deferential if the process was correctly followed. This means the legal risk post-approval is relatively low in the UK model.
China has a very different context. Public participation exists in name – projects post EIA reports for comment – but citizens or NGOs do not have independent power to sue the government over a permit decision. There is an avenue for administrative reconsideration or complaints to higher authorities, but these are rarely effective in stopping projects. In recent years, China has allowed public interest environmental lawsuits in some domains (like pollution enforcement), but not against government approvals for new projects. Essentially, the Communist Party decision-making process is the gatekeeper, and once a project is politically approved, opposition has limited recourse. That said, China’s government has its own internal checks – it sometimes conducts inspections and if a project is found violating rules or causing unrest, higher authorities may intervene. But this is an internal accountability, not a judicial one. The absence of external litigation makes the process faster, but also places a burden on regulators to get it right (or face the consequences later in terms of pollution or public anger). China’s EIA reports can be shorter and less detailed than NEPA EISs, focusing on key metrics and mitigation. Some Western analysts note that Chinese EIAs historically did not explore alternatives as deeply, nor cumulative impacts, but China is improving in those areas, especially for high-profile projects and in response to environmental goals.
Japan’s system allows for administrative lawsuits, but the bar is high. Local residents can and do file suits to stop projects (there have been cases against airport expansions, coal power plants, etc.), but Japanese courts have often been reluctant to overturn government approvals unless a clear law was violated. More often, disputes are handled through political negotiation rather than court injunctions. Culturally, there’s been an emphasis on reaching consensus or compensation agreements with affected communities (e.g., providing subsidies to towns hosting undesirable facilities) to preempt opposition. Environmental groups in Japan are less likely to sue than their U.S. counterparts, partly due to legal standing barriers and the expectation that persuasion is more effective than litigation. Thus, Japan, while procedure-heavy like the U.S., has not seen the same volume of environmental litigation. The processes are slow largely due to bureaucratic caution and thoroughness (and sometimes indecision), rather than courts ordering delays.
In terms of environmental outcomes, it’s difficult to quantitatively compare which system is “better” at protecting the environment. The U.S. can claim successes in preventing truly harmful projects (or mitigating them heavily) because of NEPA and litigation (for example, dams that would have flooded Grand Canyon stretches were halted in the 1970s). Europe can claim it has strong environmental standards integrated (the EU has very low acceptance of air/water pollution from new projects and aggressive climate policies guiding what gets built). China’s rapid build-out came with some environmental cost (e.g., higher pollution in the 2000s), though they are now trying to green their Belt and Road projects and domestic development. One measure could be public trust and conflict: Europe and Japan generally have less intense conflict around infrastructure than the U.S. does now, perhaps because their processes or compensation mechanisms have evolved to address local concerns earlier. In the U.S., polarization and distrust can make any big project a lightning rod (whether it’s a transmission line or a transit project, you will find staunch proponents and opponents).
The international comparisons suggest trade-offs: The U.S. errs on the side of thorough deliberation and legal openness, at the cost of speed. Europe seeks a middle ground – structured processes with set timeframes (in some countries) and limited but still available legal challenge routes. China prioritizes speed and centralized control, sacrificing some transparency and independent recourse. Japan follows a U.S.-like thoroughness but tries for consensus to avoid litigation. These differences inform the range of solutions and best practices that can be considered, as discussed next.
4. Policy Innovations & Best Practices
Across the surveyed regions, various policy innovations have been implemented to improve permitting efficiency without compromising environmental standards. This section highlights successful reforms and emerging best practices, grouped into categories: (a) Legislative and Administrative Reforms (laws or regulations that changed the process), (b) One-Stop and Coordinated Permitting Models, (c) Use of Technology and Digital Platforms, and (d) Case Studies of projects that navigated permitting challenges successfully.
Legislative and Administrative Reforms in the U.S. and Abroad
Several reforms in the U.S. have aimed to streamline permitting. One of the most significant is Title 41 of the 2015 FAST Act, commonly known as FAST-41. This created the Federal Permitting Improvement Steering Council and a Permitting Dashboard to track projects. FAST-41 applies to certain large, complex projects (e.g., energy, water, transportation) and brings agencies together to develop a coordinated timetable. It also shortened the statute of limitations for lawsuits to 2 years for covered projects, reducing open-ended legal uncertainty (Using FAST-41 to Streamline Federal Permitting Process). Early evidence indicated FAST-41 has helped cut some timelines – for instance, some projects under FAST-41 saw federal review times drop by a year or more due to better coordination (Why Congress Should Permanently Authorize FAST-41). However, uptake of FAST-41 was initially limited (some developers didn’t opt in), and a 2021 analysis suggested it added process without dramatically speeding approvals in all cases (Is Fast-41 Permitting All That Fast? Why Congress Must Take a More Serious Approach to Streamlining Federal Permitting). Congress made FAST-41 permanent through the 2021 Infrastructure Investment and Jobs Act, signaling confidence in its potential (Is Fast-41 Permitting All That Fast? Why Congress Must Take a More Serious Approach to Streamlining Federal Permitting).
Another U.S. initiative was One Federal Decision (OFD), an executive order under the previous administration (2017) that was partially codified in 2023. OFD sets a goal of a 2-year average for EIS completion and requires one joint record of decision where multiple agencies are involved, to avoid staggered decisions. It also assigned each major project a lead agency to shepherd it through. Agencies have been working to implement these changes, and as noted, CEQ’s 2025 report showed improvement in median EIS times. Additionally, sector-specific reforms are underway: for example, recent legislation attempts to streamline permitting of critical mineral mines and interstate transmission lines by giving the federal government more siting authority (Congressional action on energy permitting remains stuck, but states ...). While legislative efforts in 2022-2023 for a broad “permitting reform” package did not fully materialize (due to political disagreements over the extent of environmental rollbacks), pieces like the NEPA timeline limits were enacted in the debt-ceiling deal of 2023.
Internationally, there are notable reforms:
-
Germany has passed a suite of laws in the last few years to accelerate permitting. The Planning Acceleration Act (2020) and updates to sectoral laws set stricter timelines and even allow some preliminary work to start before final permit issuance in cases of public interest. As mentioned, litigation reform in 2023 is a game-changer: cases go straight to higher courts, and courts are now working under guidelines to expedite decisions for renewable energy and transport projects. Germany also increased staffing and resources for permit authorities and set up specialized units to handle renewable energy permitting at the state level to clear backlogs.
-
France introduced “le permis environnemental unique” (single environmental permit) in 2017, merging what used to be multiple permits (e.g., water, species, waste) into one process (). This reduced administrative burden on both authorities and developers. Further, France’s 2023 renewable energy acceleration law streamlines public consultation and creates a mediation process to resolve conflicts during permitting, aiming to preempt court fights.
-
The European Commission at the EU level has recognized permitting as a barrier to its Green Deal targets. In 2022, the EU issued an Emergency Regulation (EU 2022/2577) declaring renewable energy projects to be of “overriding public interest” and urging member states to designate go-to areas with simplified permitting. It sets an ambitious 12-month limit for permitting renewable projects in such areas (excluding grid connection) and 24 months elsewhere, and a 3-month limit for small (<50 kW) solar installations. These provisions are temporary (1.5 years) but likely to be integrated into a revised Renewable Energy Directive. Some countries like Spain and Portugal have also passed laws to cut red tape (Spain’s recent decree set time limits and deemed approval if authorities don’t respond in time for certain solar projects).
-
China has continually refined its process – a key innovation is the integration of Strategic Environmental Assessment (SEA). By doing regional and sectoral SEAs (like the one for the Beijing-Tianjin-Hebei region’s development), China pre-assesses environmental capacity and sets “red lines” which simplify individual project reviews (projects consistent with the plan can sail through with standard EIA, those not consistent might not even be allowed). Another innovation is use of binding targets for local officials – since officials are evaluated on meeting development goals, the system incentivizes them to get projects permitted and built. Recently, China’s central government has also pushed for improved transparency: environmental impact reports are published online for comment, and there’s a blacklist for EIA consulting firms that produce shoddy work, to improve quality.
-
Japan has made more modest tweaks: an amendment to the EIA Act in 2020 allows for earlier scoping and better information sharing, and there’s discussion of introducing statutory time frames. One specific reform: for offshore wind, Japan’s new legal framework identifies specific offshore “promotion zones” with pre-conducted environmental baseline studies and a simpler approval for projects within them, somewhat akin to zoning for wind farms. This is inspired by the Danish model.
One-Stop and Coordinated Permitting Models
One of the most effective best practices globally is creating a “one-stop-shop” for permits. Instead of a proponent chasing approvals from multiple agencies sequentially, a single lead agency or coordinated body handles the multi-agency review concurrently.
-
Denmark’s one-stop shop: Denmark, a leader in wind energy, has an integrated approach. The Danish Energy Agency (DEA) serves as a one-stop authority for permitting large energy projects. For offshore wind, the DEA coordinates all needed approvals across environment, planning, grid connection, etc., and issues a single license. This model has been praised for providing clarity and speed. The European Commission highlighted Denmark as a best practice in integrating strategic planning with environmental assessment to streamline decisions. The result is that Denmark can go from tender to construction of offshore wind in much less time. (Denmark also does much of the environmental assessment at the site identification stage – the government surveys potential offshore sites in advance, so developers don’t have to start from scratch on EIAs for each project.)
-
United Kingdom’s Planning Inspectorate essentially acts as a one-stop for NSIPs – it manages the whole examination and produces a recommendation, leaving just a yes/no decision to the Minister. Local and environmental authorities feed in their input, but the applicant isn’t left to negotiate individually with each – the process aggregates those inputs. The UK has also introduced the concept of a fast-track consent route for certain priority projects to shorten examination to 4 months (Planning for nationally significant infrastructure projects).
-
Netherlands has implemented a comprehensive reform with its new Environment and Planning Act (Omgevingswet) (expected to be in force in 2024). This act consolidates dozens of spatial and environmental plans and permits into one framework (Global Infrastructure Permitting - Competitive Enterprise Institute). Under it, a developer can submit one digital application for a project, and the authorities internally coordinate to issue one integrated decision that covers all aspects (environmental, building, water, nature). It effectively merges procedures and even has one unified legal appeals process (Global Infrastructure Permitting - Competitive Enterprise Institute). This one-stop model is among the most ambitious globally.
-
United States examples: While the U.S. doesn’t yet have a universal one-stop, there are some models. The FAST-41 Permitting Council is a coordinating body that moves things in that direction for covered projects. Some states have one-stop permit offices for state-level permits. Notably, New York State recently created the Office of Renewable Energy Siting (ORES) as a one-stop for large renewable energy project permits (over 25 MW) (US Clean Energy Goals Hinge on Faster Permitting). Rather than each wind farm going through local zoning and state Department of Environmental Conservation permits separately, ORES issues one combined permit, overriding local processes (while still considering local laws). This was designed to cut what used to be a 5-7 year slog for wind projects down to 1-2 years in New York. Early indications show promise, though ORES decisions have also faced some legal challenges. Another U.S. example is the concept of “Section 404/10 one-stop”: the Army Corps of Engineers can issue joint permits that satisfy both Section 404 of the Clean Water Act and Section 10 of the Rivers and Harbors Act and coordinate with state water quality reviews to streamline water-related permits, though this is more coordination than true single permit.
-
Australia and Canada also offer instructive models: Australia uses bilateral agreements so that states can do environmental assessments that satisfy federal law (avoiding two separate assessments). It also has a “major projects facilitation” agency. Canada’s Impact Assessment Agency now tries to conduct one unified impact assessment for federal decisions, incorporating input from provincial authorities to avoid duplication, and has legislated timelines.
The essence of one-stop permitting is reduced fragmentation. By providing a single interface to the proponent, it reduces confusion and delay. Internally, it forces agencies to talk to each other and resolve conflicts earlier. Many European countries (and some U.S. states) have found that this not only speeds up decisions but also improves compliance because the project gets a holistic review rather than piecewise approvals.
Technological and Process Innovations
Technology is playing a growing role in modernizing permitting:
- Digital Permitting Platforms: Moving away from paper and siloed systems, many jurisdictions have built online portals where developers can apply and agencies can collaborate. For example, the U.S. Permitting Dashboard (performance.gov) provides transparency on the status of federal permit reviews, which pressures agencies to stick to schedules and helps identify bottlenecks. In the EU, countries like Estonia and Finland have highly digitized permit systems for construction that cut down processing times drastically. A digital platform can incorporate checklists, GIS mapping of environmental constraints, and even automatically flag missing information.
- GIS and Data Sharing: A key innovation is creating central environmental data repositories accessible to developers. If developers can easily get data on species, habitats, cultural sites, etc., they can design projects to avoid impacts from the outset. The Energy Transitions Commission noted that governments managing better environmental data banks and sharing them could significantly speed up project preparation and permitting. Some countries now publish map-based tools highlighting areas with permitting exclusions or streamlined processes (France, for instance, published wind “acceleration zones” map; Germany’s BSH provides detailed marine spatial plans for offshore wind).
- Artificial Intelligence (AI) and Automation: This is an emerging area. AI could potentially assist in reviewing public comments (sorting thousands of comments to identify key themes or identical submissions), in environmental analysis (modeling impacts or optimizing alternatives), or in compliance monitoring post-approval (using sensors/drones to ensure a project is following environmental conditions). While still nascent, agencies are exploring machine learning to help with repetitive tasks in the permit process – for example, the scanning of infrastructure plans for compliance with regulations. Some EIA consultancies use AI tools to predict potential impacts (like noise propagation, habitat disruption) faster than manual calculations.
- Early Stakeholder Engagement and Mediation: Not a technology per se, but a process innovation is to engage stakeholders earlier and more continuously. Instead of the traditional “proponent develops project -> public comments -> conflict” model, approaches like collaborative planning are used. For example, in the Netherlands and Denmark, developers of wind projects often convene local communities at the conceptual stage to discuss layout and benefits, which can preempt formal objections later. The U.S. Department of Energy has funded processes to identify community concerns early in transmission line siting. Along the same lines, some jurisdictions have instituted mediation or arbitration during permitting. France’s new law allows the prefect (state representative) to call a mediation between developer and opponents during the permitting to find solutions, potentially avoiding a court fight.
- Programmatic Approaches: Performing broader analyses up front that individual projects can tier from is a best practice. The U.S. used this with the Solar Energy Zones – the Bureau of Land Management did a Programmatic EIS for Solar Development across six states, identifying suitable zones with low environmental conflict. Projects in those zones then received expedited, simplified NEPA reviews. This led to a boom in approved solar projects on federal land; in FY2021 alone, BLM approved 10 utility-scale solar projects totaling 2.8 GW, representing over 20% of that year’s new solar capacity nationwide. Similarly, programmatic EIAs for wind energy areas offshore have helped streamline individual project approvals by front-loading wildlife and habitat studies. China’s TLOP policy is analogous – it’s essentially a programmatic environmental zoning.
- Tracking and Accountability: Some countries have introduced permit tracking systems with accountability metrics. For example, Canada’s Impact Assessment Act requires the agency to publicly report timelines and if timelines are paused or extended, to give reasons. In the U.S., FAST-41 created a scoreboard of whether agencies meet milestones. These measures compel agencies to treat timelines as commitments. Another idea is performance-based funding – e.g., tying some portion of agency budgets to timely permit delivery, though this is not yet common.
The combination of these technological and procedural innovations leads to what one might call “Smarter Permitting.” It doesn’t necessarily reduce the substantive requirements, but makes the process more transparent, predictable, and efficient. Importantly, none of these require sacrificing environmental integrity; they are about doing the same necessary analyses in a better way.
Case Studies: Overcoming Permitting Challenges
Concrete examples illustrate how certain projects managed to break through permitting hurdles:
-
U.S. Solar Energy Zones (BLM Solar PEIS): As mentioned, the 2012 BLM Solar Programmatic Environmental Impact Statement designated 17 solar development zones on public lands in the Southwest. By resolving land-use conflicts and environmental issues at a programmatic level, individual solar projects in those zones could use a greatly simplified EA rather than a full EIS. This was a successful reform – it attracted developers to the pre-cleared areas and led to a surge of approved projects. The fact that BLM was able to approve 2.8 GW of projects in one year (2021) is evidence that front-loading the analysis and providing certainty on locations can expedite deployment of renewables.
-
Denmark’s Offshore Wind Buildout: Denmark’s approach to offshore wind is often cited as a model. For instance, the Kriegers Flak offshore wind farm (600 MW) benefited from a coordinated permitting scheme. The government performed environmental assessments of the site (in the Baltic Sea) in advance and held a tender; the winning developer could rely on those assessments and needed only to produce project-specific supplementations. The Danish Energy Agency acted as the one-stop authority. The result was that from the tender award to final permit took only around 1.5 years, and the wind farm was constructed on schedule by 2021. This contrasts with some other countries where offshore wind projects have taken much longer from concession to operation.
-
Germany’s LNG Terminal 2022: Facing an urgent need to replace natural gas supplies, Germany permitted and built an LNG import terminal at Wilhelmshaven in under a year. Normally, such a project might have required an EIS and lengthy public consultation. Instead, the government passed an emergency law (LNG Acceleration Act) that temporarily waived certain procedural steps (without waiving substantive safety/environment standards). Agencies worked concurrently on different aspects (environment, construction, port permits) and a decision was made quickly. While this was an extraordinary situation, it showcased that, when prioritized, permitting in Germany could be massively accelerated. The terminal began operation in late 2022 – a case of going from drawing board to reality in ~10 months.
-
Mountain Valley Pipeline (MVP), U.S.: This interstate natural gas pipeline (303 miles across West Virginia and Virginia) became emblematic of permitting/legal struggles. It received initial FERC approval and other federal permits by 2017, but court challenges (mainly under NEPA and the Endangered Species Act) vacated several permits (from the Forest Service, Bureau of Land Management, and Army Corps). The project stalled for years despite being half-built. In 2023, a unique solution was implemented: Congress, in the debt-limit legislation, directly mandated the completion of MVP and stripped courts of jurisdiction over it. This essentially overrode the permitting process via statute. While not a typical “best practice” (it’s not scalable or procedurally driven, but rather a one-time political intervention), it demonstrated the lengths to which policymakers might go when a project is deemed critical. It also highlighted the interplay between permitting and politics: after so many legal delays, the legislative branch stepped in to break the logjam. MVP is now on track to finish, but the case underscores that more systematic solutions are preferable to such ad hoc measures.
-
Tokyo Gaikan Expressway (Japan): This urban expressway project around Tokyo had been planned for decades. Environmental and community concerns delayed it extensively. In the 2000s, a new approach was taken: shifting much of the route into deep tunnels to address surface impacts, and a comprehensive consensus-building exercise with local governments. Permitting was done in stages for different sections. By incorporating mitigation (tunneling) directly in the design, the project won local approval. The EIA process was still time-consuming, but by proactively resolving key issues (noise, relocations) and showing environmental considerations (like measures to protect river ecosystems during construction), opposition waned. Construction began in segments and some are now open. This case shows the importance of early mitigation and engagement as a de facto “best practice” to get through Japan’s process.
-
Renewable Energy Zones in Texas (U.S.): Texas, while not a federal process example (most of its land is private and state-level), offers an interesting case. In the 2000s, Texas identified Competitive Renewable Energy Zones (CREZ) in its windy west regions and proactively built transmission lines to those zones. This policy decision streamlined the subsequent development of wind farms – once the transmission was there (permitted by the state relatively quickly, since Texas has a single Public Utility Commission process and minimal environmental review requirements compared to federal NEPA), wind projects sprung up rapidly and only needed standard state-level permits. By 2013, Texas had completed $7 billion of transmission lines, and today Texas has by far the largest installed wind capacity in the U.S. The “zone” approach avoided piecemeal permitting of each line and farm by looking at the big picture. It’s analogous to the programmatic approach at the federal level and is considered a successful case of aligning planning with permitting.
These case studies reinforce certain themes: upfront planning, integration of efforts, and political will can drastically improve outcomes. When environmental review is used not just as a compliance exercise but as a planning tool (to choose better alternatives and sites), it facilitates smoother permitting. Projects that invest in community relationships and go beyond minimum requirements tend to face fewer legal hurdles. And conversely, projects that neglected such steps often got bogged down (or required extraordinary intervention).
5. Recommendations for the U.S.
Drawing from the challenges identified and the best practices observed domestically and internationally, this report offers the following evidence-based recommendations to improve the U.S. permitting process for infrastructure and energy projects. The goal is to accelerate permitting timelines and provide greater certainty while maintaining robust environmental and public-interest safeguards. Policymakers, agency leaders, and stakeholders should consider a multi-pronged strategy:
-
Establish “One-Stop-Shop” Permitting Authorities: Consolidate and coordinate reviews under a single lead agency for major projects. For example, empower a lead agency to issue a joint environmental document and unified record of decision on behalf of all federal agencies. Building on FAST-41, consider expanding the model of a single application portal for all required federal permits. Encourage states to create similar one-stop offices for state and local permits. This reduces duplicative efforts and confusion for project sponsors.
-
Enforce Clear Timelines and Page Limits: Implement the new NEPA deadlines (2 years for EIS, 1 year for EA) aggressively across agencies, and have CEQ monitor and report on compliance. If an agency cannot meet a deadline, require written justification to Congress or a high-level task force. Deadlines should be paired with adequate resources (see below) to be realistic. The success of the CEQ’s recent timeline reduction suggests that with oversight, timelines can shrink without sacrificing quality. Additionally, enforce page limits (with exceptions for complex cases) to curb “kitchen sink” EIS documents that take too long to produce and review.
-
Increase Agency Capacity and Expertise: Under-resourced agencies are a bottleneck. Hiring additional environmental review staff, contracting support, and training can have an immediate impact. The data shows current agency staffing is at maximum capacity for processing renewables; a doubling of staff focused on permitting (for example, hiring more NEPA specialists, engineers, biologists, and attorneys) could significantly speed up reviews by enabling parallel work and quicker turnaround. Funding from the Inflation Reduction Act is already boosting agencies like FERC and the Fish & Wildlife Service in this regard – continued and expanded funding is needed. Public-private partnerships can help here: allow project proponents to fund extra staff or third-party contractors for their project’s review (under agency supervision) to ensure timely completion, a practice already used by some agencies.
-
Expand Programmatic and Tiered Reviews: Make greater use of Programmatic EIS/EAs and regional planning to front-load analyses. Identify priority areas for development (renewable energy zones, transmission corridors, etc.) through programmatic reviews that engage stakeholders and assess cumulative impacts. This can pre-clear areas with lower conflict so that individual projects can tier off those analyses and sail through in a fraction of the time. For example, the government could do a programmatic EIS for a nationwide network of high-voltage transmission corridors, which state regulators and project developers could then reference, reducing the scope of project-specific studies. Similarly, programmatic reviews for offshore wind areas in federal waters should continue and expand, as they have been effective in streamlining project-specific permitting.
-
Modernize and Harmonize Federal-State Roles: Clarify jurisdictions to avoid duplicate or sequential reviews. Wherever a state process provides equivalent rigor, allow substitution for federal review (as done in surface transportation with NEPA assignment). Conversely, for interstate projects, consider granting a federal entity siting authority to override unreasonable state delays (similar to how FERC permits interstate gas pipelines). This could apply to transmission lines – for instance, empower DOE/FERC to approve cross-state electric lines of national importance, while still consulting states. Additionally, update Section 401 of the Clean Water Act regulations to ensure states use that authority within its scope (water quality) and decide within a reasonable timeframe, to prevent inadvertent vetoes on other grounds. This doesn’t remove state input, but rather streamlines it and prevents misuse.
-
Reform Litigation Procedures (Without Removing Accountability): To reduce lawsuits that cause excessive delay, a few reforms are advisable: (1) Shorten the statute of limitations for NEPA and other environmental permit lawsuits to 150 days or 1 year (as opposed to 6 years currently for NEPA via APA), generalizing the approach used in FAST-41. This ensures any legal challenges arise quickly while the record is fresh. (2) Establish specialized environmental permit courts or judges who can handle cases on an expedited schedule, similar to how some countries route such cases to higher courts. These courts could develop expertise to resolve disputes faster and filter out frivolous claims. (3) Limit injunctions against projects that have followed a thorough process, especially after a remand – for example, allow agencies to proceed with parts of a project not in dispute while fixing a NEPA document on another part, rather than halting entire projects. (4) Encourage alternative dispute resolution – require petitioners and agencies to engage in mediation before litigation, to see if issues can be resolved (perhaps with minor project modifications or mitigation) without a court battle. Importantly, these measures still preserve the right to challenge bad decisions – they simply aim to accelerate resolution. Germany’s example of concentrating jurisdiction and moving straight to appellate review is instructive (), as is France’s approach of giving courts power to amend permits rather than just cancel them ().
-
Enhance Public Engagement and Local Benefits Early: Opposition often stems from communities feeling blindsided or bearing costs with little benefit. Therefore, institutionalize early and meaningful engagement: Agencies should convene local stakeholders at the pre-scoping stage to identify concerns and co-develop solutions (as seen in some successful Japanese and European cases). Projects that incorporate local feedback from the start tend to face fewer legal challenges. Also, promote mechanisms for local benefit-sharing – e.g., infrastructure projects could include community benefit agreements or revenue-sharing for local improvements. While this goes beyond permitting per se, it can reduce NIMBYism which is at the heart of many delays. Policymakers might create incentives or requirements for such agreements in federal funding. Additionally, improve education and transparency: use online dashboards and public meetings to demystify projects and show how impacts will be mitigated. When the public trusts the process, they are less likely to resort to lawsuits.
-
Leverage Technology for Efficiency: Adopt state-of-the-art tools to assist the permitting process. For instance, use GIS mapping tools to identify environmental conflicts (wetlands, habitats, historic sites) at the outset, helping to micro-site projects in better locations. Develop automated checklists for permit applications to ensure they are complete and flag issues early. Pilot AI-driven analysis to handle rote tasks: for example, natural language processing to sort public comments (clustering similar concerns together for a single comprehensive response) or machine learning to predict environmental outcomes under different alternatives, which analysts can then verify. Employ project management software across agencies to coordinate schedules and share documents in real-time. These improvements can shave off months of back-and-forth and reduce human error. The cost of such tools is minor relative to the savings in time. The federal government could establish a digital platform for environmental review that all agencies use, replacing the ad-hoc document exchanges with a unified system that stakeholders and the public can also access for transparency.
-
Institutionalize Best Practices from Others: The U.S. should continue to learn from international peers. For example, Germany’s approach to pre-approve renewable energy areas with streamlined reviews could be translated into U.S. public land management (e.g., expansion of BLM’s solar and wind energy zones, or Forest Service designating corridors for transmission). The UK’s strict timeline enforcement and centralized decision suggests the U.S. could set up interdisciplinary review teams that follow projects from start to finish, with leadership backing to keep to schedules. Denmark’s single authority model for offshore wind could inform how the U.S. manages offshore wind leasing and permitting – possibly consolidating the roles of BOEM, NOAA, USACE, etc., into one task force for each offshore wind project. Regular exchanges between permitting officials globally (perhaps under OECD or bilateral forums) can help cross-pollinate ideas. There is already movement on this front: the G7 has discussed the need to accelerate clean energy permitting, and sharing data on what works will be valuable.
-
Monitor, Measure, and Iterate: Finally, instituting an ongoing monitoring mechanism for permitting reform will ensure continuous improvement. The Federal Permitting Improvement Steering Council could be tasked to release annual scorecards on average review times by agency and sector, number of legal challenges, and outcomes. Congress should conduct oversight hearings to receive updates on whether recent reforms (FAST-41, FRA 2023 changes) are actually reducing delays. If not, further tweaks should be made. In addition, consider establishing a stakeholder advisory panel – including industry, environmental NGOs, state representatives, and community advocates – to identify pain points in the process and propose solutions collaboratively. This can ensure that reform efforts address real-world issues and maintain balance.
Implementing these recommendations would require concerted effort across federal agencies, legislative support, and buy-in from states and the public. However, the payoff would be substantial: infrastructure built faster, at lower cost, and with greater certainty, without undercutting the environmental protections that are so crucial. Streamlining permitting is often portrayed as deregulatory, but as the analysis in this report shows, it need not weaken environmental outcomes. On the contrary, a more efficient process can enhance environmental and social benefits by focusing resources on mitigation and smart planning rather than on protracted paperwork and court battles. By learning from both domestic experience and international models, the U.S. can reform its permitting paradigm to meet the challenges of the 21st century – from rebuilding aging infrastructure to deploying clean energy at scale – in a timely, sustainable, and publicly accountable manner.